Terms & Conditions

1.  Definitions

In this Agreement, “the Contractor” is Tested Electrical And Communications Services trading as Tested Electrical, its successors and  assigns or any person acting on behalf of and with the authority of  Tested Electrical.

 “the Customer” is the person or entity  requesting goods and services from the Contractor and named as the Customer on the Contractor’s quote, Customer information form, and other  Customer paperwork; “Goods” means all goods sold, leased, rented,  consigned, bailed or otherwise made available to the Customer by the  Contractor including but not limited to electrical equipment and associated  components.

 “Site” means the place where the Contractor’s services will be  carried out; "We" or "Us" means Tested Electrical, and “Services” mean the Contractor’s performance of electrical work and associated services.  

2. Quotes

The Contractor shall give the Customer a quote specifying the Goods and  Services required in order to fulfill the Customer’s instructions and a cost estimate for such Goods and Services.

2.1  Acceptance by the Customer    

Where the Contractor has given the Customer a quote:   

a) the Customer shall accept the quote by signing and returning a true copy of the quote accompanied by a purchase order  number, if applicable;   

b) quotes are valid for thirty (30) days only unless an extension  has been authorised by the Contractor;  

c) the Customer warrants that it has not relied on any  representation by the Contractor other than as supplied in  writing in the quote.   

2.2 Contractor May Revise Quote    

The Contractor may amend a quote, if not accepted within thirty (30) days  from the date of the quote, to take into account any rise or fall in the cost  of the Goods and Services as quoted and the Contractor shall notify the  Customer of such amendment as soon as practicable thereafter. The  Contractor will not be obliged to commence the Services until such time as  the Customer agrees to the amendment of the quote.   

2.3 Pricing   

If there is any error or omission in the Quote, Tested Electrical reserves the right to change the contract sum on the Quote. This clause  applies even if the Quote has been accepted by the customer. Prices quotes  are subject to final costing assessment by Tested Electrical.    

2.4 Force Majeure   

Tested Electrical shall not be liable for any failure or delay in  supply or delivery of the products or works where such failure or delay is  wholly or partly due to any cause or circumstances whatsoever outside the  reasonable control of Tested Electrical, including, but not  limited to war, strikes, lockouts, industrial disputes or unrest, government  restrictions or intervention transport delays, fire, act of God, breakdown of  plant, shortage of supplies or labour, storm or tempest, theft, vandalism,  riots, civil commotions or accidents of any kind.    

2.5 Products & Works   

If any products and works specified within this quotation are unavailable at  the time of works being carried out, Tested Electrical  in its  absolute discretion may substitute a reasonable alternative.  

3. Cancelation

The Customer shall reimburse the Contractor for any costs, losses or  expenses incurred by the Contractor should the Customer cancel an accepted quote. The time for payment of such cancellation shall be seven (7) days from the date of the Contractor’s invoice.

4. Work In Progress

The Customer shall provide exclusive Site access for the Contractor to complete any necessary work. Any interruptions due to no Site access or work by other trades or the Customer causing down-time may be billed at the Contractor’s hourly rate. Rates are available under section () of this Agreement.

5. Unforeseen Circumstances / Prior Work

The Contractor shall NOT be liable for any problems with the Site due to another contractor’s prior work or latent conditions which are only revealed when installing the Goods. The Contractor will carry out any work needed to fix any such problem if it is considered necessary for satisfactory installation of the Goods. Any additional work necessary due to these circumstances is a variation and subject to Clause 9. If a price is not agreed, the charge will be the actual cost plus another twenty percent  (20%) for the work.  

6. Trading Hours

The Contractor’s normal trading hours are 8am to 5pm Monday to Friday. Work performed (at the Customer’s request) outside those hours or on a public holiday will be at the Contractor’s discretion and will be subject to a surcharge. 

7. Variations

All requests for variations by the Customer or the Customer’s Agent  must be made direct to the Contractor’s office during normal business hours (8am to 5pm). The Contractor will charge the current office administration fee plus $150 ex GST irrespective as to the variation being approved or not approved.

7.1 Scope

The Customer shall indemnify the Contractor from any additional cost incurred by the Contractor should the Customer increase the scope of the Works and/or Goods to be provided. Proof that the Customer can afford the variation may be requested. 

7.2 Response

If a response to a variation requested by the Contractor has not been received from the Customer within two (2) business days, the Contractor  will carry out the Works described as part of its Scope of Works. Such variations may result in additional charges to the original Quote/Contract. 

7.3 Claims

The Customer agrees to make no claim against the Contractor for liquidated damages related to delays due to variations that were requested by the Customer. 

7.4 Variation Payment Terms

Payment terms for variations shall be seven (7) days from date of invoice. Variations within a period subject to a progress payment shall be payable at that time and no later.  

8. Payment and Default

8.1 Time For Payment

Unless otherwise agreed in writing the Contractor’s payment terms are strictly seven (7) days from the date of the Contractor’s tax invoice

8.2 Deposit

The Contractor may require a deposit from the Customer and the Customer acknowledges the Contractor is under no obligation to undertake any work  as requested by the Customer until the deposit is received by the Contractor in full and when all details pertaining to contract are finalised. In   the event of default as to payment owing to the Contractor on the part of  the Customer, the Contractor shall be entitled to forfeit the deposit and  claim any profit or margin contemplated by or allowed for in the contract in addition to any remedy available to the Contractor at law or in equity. 

8.3 Payment Claims

The Contractor shall make any payment claims in accordance with The Building and Construction Industry Payments Act 2004. The Customer must respond appropriately and within the time specified in the Act.

8.4 Payment Plans

From time to time the Contractor may offer Customers a payment plan, spreading payment over a specified period with reoccurring payments. A formal Payment Plan Agreement would need to be entered into and such an agreement would include the Contractor’s Terms and Conditions of Trade. 

8.5 Administration Fee

The Contractor reserves the right to charge a Weekly fee of twenty-five dollars ($25) for any accounts not paid within the Contractor’s agreed payment terms. 

8.6 Interest

The Contractor may charge interest at fifteen percent (15%) per annum calculated on a daily basis on amounts not paid within the Contractor’s payment terms.

8.7 Damages

The Customer must pay to the Contractor any costs, expenses or losses incurred by the Contractor as a result of the Customer’s failure to pay to the Contractor all sums outstanding as owed by the Customer to the Contractor including without limiting the generality of the forgoing any debt  collection and legal costs incurred in enforcing payment on a solicitor and own client basis. 

9. Retention Of Title

Notwithstanding the delivery of the Goods or their installation, title in any  particular Goods shall remain with the Contractor regardless of whether the Goods are on-sold by the Customer until the Customer has paid and discharged any and all monies owing pursuant to any invoice issued by the  Contractor for the Goods, including all applicable GST and other taxes, levies and duties.

Where the Goods have been on-sold by the Customer, the Customer will be taken to hold the proceeds of sale of such Goods upon trust for the Contractor and to account to the Contractor for these proceeds. 

Any payment made by or on behalf of the Customer which is  later avoided by the application of any Statutory Provisions shall be deemed not to discharge the Contractor’s title in the Goods nor the  Customer’s indebtedness to the Contractor and, in such an event, the parties are to be restored to the rights which each respectively would have  had if the payment had not been made. 

9.1 Bailment

The Customer acknowledges that it is in possession of the Goods solely as Bailee until payment of all invoices for the Goods is made pursuant to clause 9 and until that time the Customer must not encumber or otherwise charge the Goods and the Customer shall be fully responsible for any loss or damage to the Goods whatsoever and howsoever caused following delivery of the Goods.

9.2 Repossession

The Customer hereby irrevocably grants to the Contractor the right, at its sole discretion, to remove or repossess any Goods from the Customer and sell or dispose of them, and the Contractor shall not be liable to the Customer or any person claiming through the Customer and the Contractor shall be entitled to retain the proceeds of any Goods sold and apply same  towards the Customer’s indebtedness to the Contractor.

If the Customer commits an act of bankruptcy, enters into any form of administration or liquidation, makes any composition or arrangement with its creditors, ceases to carry on business or breaches any fundamental clause of this agreement, then the Contractor may, without prejudice to any other  remedies it may have, repossess any Goods delivered to the Customer on any account which has not been paid in accordance with the Terms and Conditions herein and commence proceedings to recover the balance of any monies owing the Contractor by the Customer. 

10. Personal Property Security's Act (PPSA) 

In this clause, the following words have the respective meanings  given to them in the PPSA: Financing Statement, Financing Change Statement, Proceeds, Register, Security Agreement, Security Interest and Verification Statement. In this clause “the Customer” is the grantor and “the Contractor” is the secured party, as defined in the PPSA. 

10.1 Acknowledgement

The Customer acknowledges and agrees:   

a) that these Terms and Conditions constitute a Security  Agreement that creates a Security Interest in all Goods (and  Proceeds): (i) previously supplied by the Contractor to the  Customer; (ii) to be supplied in the future by the Contractor to  the Customer;   

b) that the Security Interest created by these Terms and Conditions  is a continuing Security Interest in all Goods (supplied now or in  the future by the Contractor to the Customer) and Proceeds,  which will operate (despite any intervening payment or  settlement of account) until the Contractor has signed a release; and  

c) to waive its rights under section 157 of the PPSA and the following subsections of section 115 of the PPSA, which will not  apply to the Security Agreement created by these Terms and Conditions: 95, 118, 121(4), 130, 132(4), 135, 143. 

10.2 Customer Responsibility 

The Customer undertakes to:   

a) Keep all Goods free of any charge, lien or Security Interest except  as created under these Terms and Conditions and not otherwise  deal with the Goods in a way that may prejudice any rights of the  Contractor under these Terms and Conditions or the PPSA;   

b) Sign any further documents and provide any further information (which must be complete, accurate and up-to-date in all respects) that designer may require to: (i) register a Financing Statement or Financing Change Statement in relation to a Security Interest on the Register; (ii) register any other document required to be registered by the PPSA; or (iii) correct a defect in a statement referred to in clause 12.3(b) (i) or 12.3(b) (ii);   

c) Indemnify, and upon demand reimburse the Contractor for all  fees (including actual legal fees on a solicitor/own Customer basis), costs, disbursements and expenses in: (i) registering and maintaining a Financing Statement or Financing Change Statement on the Register or releasing any Goods charged thereby; and (ii) enforcing or attempting to enforce the Security Interest created by these Terms and Conditions.   

d) Not register, or allow to be registered, a Financing Statement or a Financing Change Statement in respect of the Goods, or Proceeds in favour of a third party, without the prior written consent of the  Contractor; and   

e) Immediately advise the Contractor of any material change in its business details (including, but not limited to, it’s trading name, address, fax number) or business practices. 

11. Warranties 

To the extent required by the Australian Consumer Law (“ACL”), the Contractor warrants that:  

a) the Works will be carried out in accordance with all relevant laws and legal requirements in an appropriate and skilful way, in accordance with the plans and specifications (where relevant)  using Goods that are good and suitable for the purpose for which they are intended to be used and that, unless otherwise stated in  the Contract, those Goods will be new; and   

b) each provisional sum item allowance, if calculated by the Contractor, has been calculated with reasonable skill and care, having regard to all the information reasonably available when the Contract is entered into (including information about the nature and location of the Site). 

11.1 

The Contractor warrants that the Works are, and that Goods supplied are, free of defects at the time of completion and/or installation.

11.2 

If the Contractor be directed to reuse any materials or components from the Site or elsewhere, then the Contractor will not accept any responsibility for the aesthetic finishes, structural entity or any warranties whatsoever attached to those materials or components. The Customer shall indemnify the Contractor from any costs, losses or expenses associated with the rectification or resupply of such materials or components. 

11.3

Subject to the ACL, the Contractor does not have to fix any problem caused by misuse, abuse, wear and tear, damage caused by vermin, lizards and insects, or normal shrinkage or movement, minor colour variation in natural products, work done by others or any defects in Goods supplied by the Customer.

12. Liability

12.1 Non-excludable Rights

The parties acknowledge that, under the Australian Consumer Law, certain  conditions and warranties may be implied in these Terms and Conditions  and there are rights and remedies conferred on the Customer in relation to  the provision of the Goods and Services which cannot be excluded,  restricted or modified by the contract (“Non-excludable Rights”). 

12.2 Disclaimer Of Liability

The Contractor disclaims all conditions and warranties expressed or implied, and all rights and remedies conferred on the Customer, by statute, the common law, equity, trade, custom or usage or otherwise and all those conditions and warranties and all those rights and remedies are excluded  other than any Non-excludable Rights. 

To the extent permitted by law, the liability of the Contractor for a breach of a Non-Excludable Right is limited, at the Contractor’s option, to the supplying of the Goods and Services again or payment of the cost of having the Goods and Services supplied again. 

12.3 Indirect Losses

Notwithstanding any other provision of these Terms and Conditions, the  Contractor is in no circumstances (whatever the cause) liable in contract,  tort including without limitation, negligence or breach of statutory duty or  otherwise to compensate the Customer for:   

a) any increased costs or expenses;   

b) any loss of profit, revenue, business, contracts or anticipated  savings;   

c) loss or expense resulting from a claim by a third party; or 

d) any special, indirect or consequential loss or damage of any nature whatsoever caused by the Contractor’s failure to complete or delay in completing the Services within a reasonable time.

12.4 Force Majeure

The Contractor will have no liability to the Customer in relation to any loss, damage or expense caused by the Contractor’s failure to complete the Services or to deliver the Goods as a result of fire, flood, tempest, earthquake, riot, civil disturbance, theft, crime, strike, lockout, breakdown, war, the inability of the Contractor’s normal suppliers to supply products or any other matter beyond the Contractor’s control. 

13. Privacy

The Customer authorises the Contractor to collect, retain, record, use  and disclose commercial and/or consumer information about the Customer,  in accordance with the Privacy Act 1988 and the Privacy Principles outlined in the Privacy Amendment Act 2012, to persons and/or legal entities who  are a solicitor or any other professional consultant engaged by the Contractor, a debt collector, credit reporting body and/or any other individual or organisation which maintains credit references and/or default  listings. This information may be given before, during or after the provision of credit to the Customer. 

13.1 Subject To Privacy

Subject to the Privacy Principles outlined in the Privacy Amendment Act 2012, the Customer further authorises the Contractor to collect, retain, record, use and disclose personal information for the marketing of Goods and Services provided by the Contractor. 

14. Arbitration And Mediation

Any dispute or difference between the Customer and the Contractor may be notified by a party to the other party and the parties shall firstly meet to negotiate, in good faith, resolution of the dispute and secondly, if negotiation fails to achieve a resolution of the dispute within five (5) working days of the notification of the dispute, attend mediation, administered in accordance with procedures as set out by the Institute of Arbitrators and Mediators Australia, provided that this provision shall not prevent the Contractor from instituting legal action at any time to recover monies owing by the Customer to the Contractor.

15. Security And Charge

The Customer hereby charges all property, both equitable and legal, present or future of the Customer in respect of any monies that may be owing by the Customer under these Terms and Conditions or otherwise and  hereby authorises the Contractor or its solicitors to execute any consent form as its attorney for the purpose of registering a caveat over any real property owned by the Customer at any time.

16. General Matters

16.1 Non-Waiver

Failure by the Contractor to enforce or delay in enforcing any right or  provision of these Terms and Conditions will not constitute a waiver of such right or provision unless acknowledged by in writing. 

16.2 Amendments To These Terms and Conditions 

The Contractor reserves the right to vary these Terms and Conditions at any time with notice in writing to the Customer. Any approved quote or work order will represent the Customer’s agreement to these Terms and Conditions as amended. 

16.3 Severability  

Any provision in these Terms and Conditions which is invalid or unenforceable in any jurisdiction must be read down for the purposes of  that jurisdiction, if possible, so as to be valid and enforceable. If that provision cannot be read down then it is capable of being severed to the extent of the invalidity or unenforceability without affecting the remaining provisions of these Terms and Conditions or affecting the validity or enforceability of that provision in any other jurisdiction. 

17. Tenancies Safety Inspections

17.1 Servicing Areas

Call Outs & Inspections further than a 60km Radius from Melbourne CBD may occur an additional fee of $80.00+gst unless stated otherwise.

17.2 Electrical Compliance Inspections

Tested Electrical are Licenced and Insured to undertake all Electrical Safety Inspections in accordance with AS/NZS 3019. Inspections are only to Identify Issues by means of Visual Inspection & Testing, Any works required it will be an additional cost.

17.3 Gas Compliance Inspections

Tested Electrical are Not licensed to undertake the Gas Inspections. We have Engaged a third party who are Licensed to undertake the work. All organisation is done through Tested Electrical.

17.4 Smoke Alarm Inspections

Tested Electrical are Licenced and Insured to undertake all Smoke Alarm Safety Inspections in accordance with AS/NZS 3786:2014 . Inspections are only to Identify Issues by means of Visual Inspection & Testing, Any works required it will be an additional cost.